Download the contract form for plastic windows. Sample contract agreement for the installation of PVC windows, concluded between an individual and a legal entity

Contract for the supply of plastic windows No. __

_______________ "___"___________2011G.

Society with limited liability ________________________, represented by director __________________, acting on the basis of the Charter, on the one hand, and _________________________________, represented by director _______________________, acting on the basis of ____________________________, hereinafter referred to as the “Customer”, on the other hand, have entered into this agreement as follows:

1. THE SUBJECT OF THE AGREEMENT

1.1. The Contractor undertakes to manufacture according to dimensions, sketches, quantity, in accordance with Appendix No. 1, which is an integral part of this contract, dismantle and install plastic windows with window sills and ebbs (hereinafter referred to as Windows), in the premises _____________, located at the address: ______________________________, and the Customer undertakes to accept products and pay for them on the terms established by the contract.

1.2. The work is carried out by the Contractor from own materials and on your own.

1.3. The risk of accidental death or accidental damage to the result of work and windows is borne by the Contractor until the acceptance of this result by the Customer. This fact is confirmed by the acceptance certificate for completed work signed by the parties.

1.4. Ownership of the windows under this contract passes to the Customer after signing the work completion certificate.

1.5. The warranty period for Work and windows is 1 (one) year from the date of signing the certificate of completion of work.

2. RIGHTS AND OBLIGATIONS OF THE PARTIES.

2.1. Rights of the Customer:

At any time, check the progress and quality of work performed by the Contractor, without interfering with its activities;

Change the terms of this agreement in relation to the result of work provided for in the Order, or cancel the agreement at any time, subject to reimbursement to the Contractor for the costs incurred, taking into account the time spent in connection with the execution of this agreement.

2.2. Responsibilities of the Customer:

Provide a room prepared for work on dismantling old window units and installing new ones, including supplying 220V electricity to the work site.

Accept the result of the work performed by the Contractor, if there are no obvious deficiencies in it;

If hidden defects are discovered as a result of the work, notify the Contractor within three working days from the moment of discovery;

Pay for the work performed in the manner and amount provided for in this agreement;

2.3. Responsibilities of the Contractor:

Complete the entire range of work under this agreement within 2 (two) weeks from the date of receipt of the advance payment provided for in clause 3.2. actual agreement.

Transfer the result of the work to the customer according to the certificate of completion;

Warn the Customer about the occurrence of circumstances that threaten the suitability or durability of the results of the work performed and do not depend on the Contractor, and suspend the work until receiving instructions from him. The occurrence of the above circumstances must be confirmed by the relevant act and other documents necessary in such cases;

Deliver the Windows to the work site using your own resources and resources.

The Contractor guarantees payment of all taxes, fees, duties related to the fulfillment of the terms of this agreement.

Cleaning and removal of garbage, removal of dismantled products, cutting polyurethane foam after installation.

3. PRICE AGREEMENT.

3.1. The total cost under this agreement is: _______________(______________________) rubles ___ kopecks, including VAT-18% - ____________ (_________________________) rubles __ kopecks.

3.2. Payment is made in next order:

50% of the contract value, which is ____________ (__________________________) rubles ___ kopecks, including VAT-18% __________ rubles,

The final payment in the amount of ____________ (__________________________) rubles ___ kopecks, including VAT-18% __________ rubles, is made within 10 working days after receiving the signature of the work completion certificate by the parties.

3.3. The price of the Agreement remains unchanged throughout the term of the agreement.

3.4. The Contractor guarantees payment to the budget of all taxes, fees and duties related to the fulfillment of the terms of this agreement.

5. PROCEDURE FOR ACCEPTANCE (RESULT) OF WORK

5.1. Acceptance of windows by the Customer for quality is carried out at the installation site: with the execution of a certificate of completion of work.

5.2. If defects are detected, a note is made in the report and a deadline is set for their elimination.

5.3. Elimination of deficiencies is carried out at the expense of the Contractor.

6. OTHER CONDITIONS.

6.1. The Contractor is responsible for poor quality materials provided by him, as well as for the provision of materials encumbered by the rights of third parties, in the manner prescribed by the current legislation of the Russian Federation.

6.2. In case of non-fulfillment or improper fulfillment by the Contractor of its obligations for the timely execution of the Agreement, it is obliged to pay the latter a penalty (penalty) in the amount of 0.1% of the value of the Agreement for each day of delay.

6.3. This agreement may be amended or supplemented by agreement of the parties. All changes and additions to this agreement are signed by both parties and are its integral parts.

6.4. This agreement may be terminated early on other grounds provided for by the current legislation of the Russian Federation.

6.5. In all other respects not provided for in this agreement, the parties will be guided by current legislation.

6.6. This agreement has been drawn up in two copies having equal legal force, one for each of the parties.

6.7. The Agreement comes into force and is valid until ________________________.

In our country, every consumer has the right to a guarantee of the quality of the products he purchases. For all companies, the contract for installing windows looks approximately the same, and buyers are not used to reading it carefully. However, an incorrectly drafted document can cause problems.

Which plastic windows are best to choose?

Choosing a plastic window is a very important step. The warmth and comfort of your home depends on how correctly you can choose it. Basic requirements for window design are:

• low thermal conductivity. In this case, the window reliably protects the room from cold in winter and heat in summer;
• good sound insulation. This is especially important if the house or apartment is located in a noisy area;
• good tightness. A high-quality plastic window, being tightly closed, has no gaps through which air passes.

STOP HEATING THE STREET!

One of the most noticeable global trends of our time is the optimization of energy intensity in all areas of life. Our country, which has huge hydrocarbon reserves, has not paid attention to this global trend for a long time. But since the beginning of the 2000s, the need to improve the energy efficiency of the economy has become obvious not only to specialists, but also to authorities and ordinary people. We are finally stopping heating the streets and starting to use energy resources more carefully.

Beware of seasonal sellers or ways to deceive the buyer.

In the course of our many years of work, we often encounter requests from desperate people who want to carry out repairs or re-installation of poor quality installed windows. When clarifying why the client does not want to contact the company that installed this window (after all, there must be guarantees on the product and installation!), we hear something sad or angry:

“Where will you find them now?”

We respect and value our clients, so we want to warn you against the mistake of contacting fly-by-night companies, which could lead to a large number of frayed nerves, a series of endless repairs and, as a result, large expenses.

Such companies are becoming more and more common in times of crisis - after working for several months and collecting money from clients, they disappear in an unknown direction, not caring about fulfilling their obligations.

Now we will try to figure it out,

how a consumer can identify from a variety of companies presented those that pose a potential danger.

on PVC installation windows Gr. , passport: series, No., issued, residing at: , hereinafter referred to as “ Customer", on the one hand, and in the person acting on the basis of, hereinafter referred to as " Executor", on the other hand, hereinafter referred to as the "Parties", have entered into this agreement, hereinafter " Agreement”, about the following:

1. THE SUBJECT OF THE AGREEMENT

1.1. Under this Agreement, the Contractor installs PVC windows in accordance with the completed Order (Appendix No. 1 to this Agreement, which is an integral part of the Agreement).

1.2. The Customer undertakes to timely sign Appendix No. 1 to this Agreement, provide the Contractor with appropriate conditions at the site for the implementation of this Agreement, accept and pay for the work performed by the Contractor in accordance with this Agreement.

1.3. All wishes of the Customer are recorded in Appendix No. 1; oral agreements do not have the force of an Agreement.

1.4. If the Customer wishes to make changes after signing Appendix No. 1 to the Agreement, these changes are recorded in writing in Appendix No. 2 and are paid additionally.

2. PROCEDURE FOR EXECUTION OF THE AGREEMENT

2.1. The contractor carries out installation based on the following order:

2.1.1. The Customer agrees with the Contractor on the scope and price of work, in the installation order Appendix No. 1, on the basis of which the Contractor prepares and transfers to the Customer the following documents:

• Agreed order and installation diagram (Appendix No. 1 to this Agreement).
• Contract for installation of PVC windows.

2.1.2. After the Customer signs this Agreement and Appendix No. 1, the Agreement is considered to have entered into force.

2.1.3. Installation is carried out within working days.

2.2. The Customer accepts the Contractor's work on installation "" 2019.

2.3. The Customer is obliged to pay the Contractor the cost of the work performed in accordance with this Agreement and Appendices No. 1, No. 2 to this Agreement upon completion of installation.

H. PRICE AND AMOUNT OF THE AGREEMENT

3.1. Payment is made at the prices of this Agreement and includes the cost of PVC products and installation work in accordance with Appendices No. 1, No. 2.

3.2. The total amount of the contract is rubles.

3.3. The advance payment is rubles.

4. PAYMENT PROCEDURE

4.1. Upon signing this Agreement, the Customer pays an advance payment.

4.2. After completion of work under this Agreement, the Customer pays the Contractor the remaining portion of the total amount of this Agreement, which is rubles.

4.3. All payments between the Contractor and the Customer under this Agreement are made in rubles based on the legislation of the Russian Federation.

5. RESPONSIBILITY OF THE PARTIES

5.1. The parties do not have the right to transfer their rights and obligations to fulfill the terms of this Agreement to third parties without the written consent of the other party.

5.2. In case of violation of the deadline for delivery of the work performed, specified in this Agreement, due to the Contractor’s fault, the Contractor shall pay the customer a penalty in the amount of % of the Contract amount for each day of delay, but not more than % of the Contract amount. If the deadline for delivery of completed work is violated due to the fault of the Customer (the Customer did not provide timely access to the Contractor’s employees and proper conditions for the Contractor to fulfill this agreement), the Customer pays the Contractor a penalty in the amount of % of the Contract amount for each day of delay, but not more than % of the contract amount .

5.3. When signing the Agreement, the Customer is obliged to check and approve the installation locations and structural configuration reflected in Appendix No. 1. After signing the Agreement and Appendix No. 1, the Customer's claims regarding configuration and design will not be accepted.

5.4. The contractor is responsible only for the work performed. In the event of a violation of the Customer's device technology, the Contractor is obliged to notify the Customer about this in writing in Appendix No. 2; in this case, the Contractor does not bear responsibility for the quality of work.

6. CIRCUMSTANCES OF FORCE MAJEURE (FORCE MAJEURE)

6.1. In case of force majeure (fire, flood, earthquake and others) natural disasters, riots, strikes, as well as regulatory acts of authorities government controlled etc.), if they affected the parties’ fulfillment of obligations, the parties are not liable. In this case, the deadlines for completing work under this Agreement are postponed in proportion to the duration of the above-mentioned force majeure circumstances, if they affected the timely execution of the Agreement.

7. TERM OF THE AGREEMENT

7.1. This Agreement comes into force from the moment it is signed and is valid until the Agreement is executed by both parties.

7.2. The Contractor guarantees to the Customer that installation work will be completed with proper quality for a period of months.

8. ADDITIONAL TERMS

8.1. The property liability of the parties is regulated in accordance with the current legislation of the Russian Federation. All disputes and disagreements that may arise between the parties are resolved by contract. If the parties cannot reach an agreement, then all disputes are resolved in in the prescribed manner in accordance with the current legislation of the Russian Federation.

8.2. The Contractor reserves the right to carry out photo control of production installation work.

8.3. The Agreement is drawn up in 2 copies, one of which is kept by the Contractor, and the second by the Customer.

8.4. All changes and additions to this Agreement are made only by mutual agreement of the parties and are drawn up in writing.

8.5. Early termination of this Agreement is carried out only by mutual agreement of the parties, and is documented in writing.

8.6. The Customer must submit claims regarding the quality of installation work to the Contractor only in writing.

8.7. From the moment of signing this Agreement, oral agreements become invalid.

9. LEGAL ADDRESSES AND BANK DETAILS OF THE PARTIES

Customer Registration: Postal address: Passport series: Number: Issued by: By: Telephone:

Executor Legal address: Postal address: INN: KPP: Bank: Cash/account: Correspondent/account: BIC:

10. SIGNATURES OF THE PARTIES

Customer_________________

Performer _________________

Please note that the contract agreement was drawn up and checked by lawyers and is exemplary; it can be modified taking into account the specific conditions of the transaction. The Site Administration is not responsible for the validity of this agreement, as well as for its compliance with legal requirements..

Russian Federation production and installation of plastic windows Executor", on the one hand, and in the person acting on the basis of, hereinafter referred to as " in a person acting on the basis, hereinafter referred to as "", on the other hand, hereinafter referred to as the "Parties", have entered into this agreement, hereinafter " Agreement”, about the following:

1. THE SUBJECT OF THE AGREEMENT

1.1. The Contractor undertakes to ensure production and delivery, and the Buyer undertakes to accept and pay for the Goods in accordance with the Specification (Appendix No. 1 to the Agreement), which is an integral part of this Agreement.

1.2. The quantity, assortment, configuration and configuration of the Goods are determined in the Specification to the Agreement (Appendix No. 1 to the Agreement), which is an integral part of this Agreement.

1.3. At the Buyer's request, the Contractor also provides other services (dismantling, installation, finishing of slopes, etc.). The types, volumes and contractual cost of work performed by the Contractor are determined in the Application for installation (Appendix No. 2 to this Agreement).

1.4. The Contractor measures the window and door openings on the basis of which the Goods will be manufactured. The measurement results are recorded in the Specification to the Contract (Appendix No. 1) and signed by the Buyer.

2. RIGHTS AND OBLIGATIONS OF THE CONTRACTOR

The performer is obliged:

2.1. Transfer to the buyer the Goods, which must correspond to the selected sample, Specifications to the Contract (Appendix No. 1) to the address: . Telephone: .

2.2. Until the transfer of the Goods, ensure its safety.

The performer has the right:

2.3. If it is impossible to fulfill your obligations in accordance with clauses 1.1,2.1,2.2, terminate the contract with the return to the Buyer of the amount paid by him and payment of compensation for the period from the moment of payment for the goods until the day the Buyer returns the amount paid by him, calculated in accordance with the refinancing rate of the Central Bank of the Russian Federation for return day.

2.4. If work is performed under clause 1.3 of this contract, the Contractor independently determines the procedure and technology for performing the work in accordance with the requirements regulatory documents: SNiPs, GOSTs, recommendations of PVC and aluminum manufacturers.

2.5. The Contractor has the right to involve third parties in performing work within the scope of this Agreement.

2.6. The contractor is considered to have fulfilled his obligations under the contract from the moment he signs the acceptance certificate for the work performed.

3. RIGHTS AND OBLIGATIONS OF THE BUYER

The buyer has the right:

3.1. Receive for review information about the Contractor that is not a trade secret.

3.2. Make changes to the configuration and configuration of the Goods on the day of execution of the contract within hours on the basis of an addendum to the contract, which is signed by the Parties.

The buyer is obliged:

3.3. From the moment of measurement, do not take actions that could lead to changes in the dimensions and (or) configuration of the openings for which the Product will be manufactured.

3.4. Provide the Contractor with the opportunity to transfer the goods: presence at specified address on the day of delivery of the buyer himself or his authorized representative, preparation of premises for warehousing and storage of the Goods, acceptance of the goods on the day specified in clause 4.1 of this Agreement.

3.5. Upon receipt of the Goods, check its appearance, configuration, quantity or assortment and sign the invoice (delivery certificate). In case of any claims regarding appearance, completeness, quantity and assortment, indicate all claims in the invoice or in the delivery certificate. Otherwise, claims will not be accepted.

3.6. When performing other services (clause 1.3 of the Agreement), the Buyer is obliged to ensure the possibility of performing work under this Agreement:

• be located at the installation address of the PVC (aluminum) Product;
• provide free access to the site of installation of PVC (aluminum) Products;
• provide the work site with electricity;
• take measures to protect interior decoration premises from contamination and minor damage that may be caused by normal actions for such work.

3.7. The Buyer or his authorized representative is obliged to sign the Work Acceptance Certificate (Appendix No. 4 to the Contract) upon completion of the work under the Contract. If there are any comments on the work performed, the Buyer indicates them in the appropriate paragraph of the Work Acceptance Certificate.

4. DATES FOR COMPLETION OF WORK

4.1. The Contractor delivers the Goods to the Buyer in 2019, subject to payment of the cost under the Agreement in accordance with the terms of Section 5. If the Buyer is unable to accept the goods on the specified day, he is obliged to notify the Contractor the day before no later than 10:00, otherwise delivery will be made at the Buyer’s expense .

4.2. The deadline for construction, installation and finishing work is business days from the day following the day of delivery.

4.3. In case of suspension of work under this Agreement at the request of the Buyer or due to unfavorable weather conditions(air temperature below -15 C, strong wind etc. p), as well as the Buyer’s failure to fulfill the obligations provided for in clauses 3.6 and 5.3 of this Agreement, the period for completing the work is increased for the duration of the suspension of the work or for the period of the Buyer’s failure to fulfill its obligations.

4.4. If the finished Goods do not match the dimensions of the existing window opening identified during the dismantling process, the Contractor has the right to increase the period of work under the contract by working days.

5. PAYMENT PROCEDURE

5.1. At the time of conclusion of this agreement, the cost of the Goods corresponds to rubles, including VAT.

5.2. The buyer produces advance payment for the Goods on the day of conclusion of the Agreement in the amount of % of the value of the Agreement, which is rubles, including VAT.

5.3. The remaining amount in the amount of rubles is paid upon delivery of the Goods to the Buyer, before the start of construction, installation and finishing work.

5.4. Payment procedure: cash - to the Contractor's cash desk or non-cash - to the Contractor's bank account within days from the date of invoice.

5.5. The fact of payment is the receipt of funds at the cash desk or to the account of the Contractor. The Buyer, in the case of a non-cash form of payment, must confirm the payment made for the Goods within banking days from the date of payment by message indicating the date and number payment document, or by providing the Contractor by fax or postal copy payment order with the bank's mark on execution.

5.6. If it becomes necessary to carry out additional work agreed upon by the parties that is not provided for in this agreement, the Buyer must pay for this work.

6. DELIVERY AND ACCEPTANCE OF GOODS

6.1. The Contractor undertakes to deliver the Goods to the Buyer at the specified address within the time period agreed upon by the Parties. The transfer of the Goods is carried out by handing them over to the Buyer who presented the original of this agreement, or by handing over the Goods to any other person who presented the Agreement.

6.2. If the delivery of the Goods does not take place within the time period agreed upon by the parties due to the absence of the buyer or his authorized representative, the Contractor shall deliver and transfer within other terms also agreed upon by the parties, and the buyer shall pay the Contractor compensation for re-delivery in the amount of rubles.

6.3. When self-pickup, after receiving notification from the Contractor about the readiness of the Goods, the Buyer is obliged to remove it from the warehouse within days. For storage of the Goods in a warehouse for more than days (both during pick-up and re-delivery due to the Buyer’s fault), the Buyer pays the Contractor % of the cost of the goods for each day of storage.

6.4. The Buyer is obliged to inspect and accept the Goods delivered by the Contractor (see clause 3.5 of the Agreement). The transfer of the Goods is formalized by signing the invoice (delivery certificate). Ownership of the Goods passes to the Buyer at the time of transfer (signing of the invoice).

7. WARRANTY

7.1. The Contractor guarantees the manufacture of products from PVC (aluminum) profiles, according to the selected sample and noted in the Specification to the Contract (Appendix No. 1).

7.2. The warranty period for Products begins from the date of signing the certificate of work performed and lasts for years.

7.3. The Contractor's warranty period for construction, installation and Finishing work is calculated from the date of signing the Work Acceptance Certificate and is one year.

7.4. During these periods (clauses 7.2 and 7.3.), malfunctions that arose through the fault of the manufacturer or the Contractor are eliminated by the Contractor within a calendar day from the date the Buyer submits a request for their elimination. The Contractor has the right to conduct a quality check. If the buyer's requirements are confirmed by verification, the Contractor undertakes to eliminate the defects at his own expense, or replace defective goods or its element (you), to a high quality level, on the basis of an appropriate agreement signed by the Parties. Warranty service is not provided in the following cases:

• installation of the Product by the buyer or third parties;
• violation of the Contractor's recommendations for storage, transportation, operation of the Goods;
• failure to comply with the provisions contained in the “Warranty Card” Appendix No. 3 to the contract;
• intentional damage to the Goods;
• carrying out repairs by persons who do not have the appropriate authority to do so from the Contractor or manufacturer.

7.5. After the warranty period expires, the Contractor provides paid service for the Product.

7.6. Service maintenance includes:

• preventive repair of locking mechanism components;
• repair, replacement of damaged components and parts.

7.7. Service is also provided by the Contractor in the cases specified in clause 7.5 of this Agreement.

8. TERM OF THE AGREEMENT

8.1. This Agreement comes into force on the day the Contractor actually receives payment for the Goods and terminates after the Parties fulfill their obligations under it.

9. RESPONSIBILITY OF THE PARTIES

9.1. In case of failure to fulfill or improper fulfillment of their obligations under this Agreement, the Parties shall be liable in accordance with the current legislation of the Russian Federation and the terms of this Agreement.

9.2. For delay in production of the product, the Contractor pays compensation to the Buyer according to the refinancing rate of the Central Bank of the Russian Federation, which is % for each day of delay from the final contract price for Products not manufactured on time, but not more than % of the amount of Products not manufactured on time.

9.3. The Contractor is not responsible if the size of the finished Goods does not match the openings intended for its installation, if:

• the measurement results were provided by the Buyer;
• in the process of dismantling old frames, hidden defects structures or deviations from SNiP allowed during the construction of the building;
• The Buyer changed the size and (or) configuration of the openings for which the Product was selected;

9.4. In case of dismantling from the installation location old box, frames, windows and doors, the Contractor is not responsible for their complete or partial destruction, as well as for the destruction of slopes provided for by the installation technology of PVC products.

10. DISPUTE RESOLUTION

10.1. The parties are doing everything necessary steps to resolve disputes and disagreements arising in connection with the execution of this Agreement through negotiations.

10.2. If the parties are unable to resolve disputes and disagreements arising in connection with the execution of this Agreement through negotiations, these disputes and disagreements are subject to consideration and resolution in accordance with the current legislation of the Russian Federation.

11. GENERAL PROVISIONS

11.1. This Agreement is full text The Agreement, and all previous negotiations, oral or written, regarding the relations of the parties regulated by the Agreement are considered invalid.

11.2. All changes and additions to this Agreement are valid only if they are made in writing and signed by both parties.

11.3. If the Buyer unmotivated refuses to sign the acceptance certificate for the work performed, a note about this is made in it, and the certificate is signed by the Contractor. In this case, the work is considered accepted by the Buyer.

11.4. All notifications having legal force or the force of an agreement under this Agreement are made in writing.

AGREEMENT No. ____________ Date of conclusion: ____.____._______

Limited Liability Company "_____________________________________________",

Citizen(s)______________________________________________________________________________
(Full Name)
residing at:

_________________________________________________________________________________

having an identity document:

Passport. series: ___________, N: ____________, date of issue: ____________, issued by: ________________________________ hereinafter referred to as “Customer”, on the other hand, have entered into this agreement as follows:

1. The Subject of the Agreement

1.1. In accordance with and on the terms of this agreement, the Contractor undertakes to perform for the Customer work on the manufacture, delivery and installation (installation) of metal-plastic structures* from PVC profile company __________________ (hereinafter referred to as the products), and the Customer undertakes to create conditions for the Contractor to properly perform the named work, accept the results of the work performed and pay for them.

1.2. The Contractor undertakes to perform the work in the manner and on the terms agreed upon by the parties in the invoice, which is an integral part of this agreement. The contractor performs work in compliance with the mandatory requirements of GOST 30674-99 “Window blocks made of polyvinyl chloride profiles”, GOST 23166-99 “Window blocks. Are common technical specifications", GOST 30971-02 "Mounting seams of junctions of window blocks to wall openings."

1.3. The Contractor guarantees the preservation of the quality and performance of the products, subject to the Customer’s compliance with the operating rules specified in the Product Warranty Card for the next warranty periods:
- for metal-plastic structures for ______ years, from the moment of transfer to the Customer;
- for installation for ________ years, from the moment the results of the work are transferred to the Customer (guarantees do not apply to products measured, delivery and installation of which were not carried out by the Contractor).

1.4. The Contractor guarantees that all materials and components used in the products have the appropriate certificates and permits. The Contractor guarantees that the quality of the work performed meets the mandatory requirements of state standards of the Russian Federation. At the time of concluding this agreement, the Customer was warned by the Contractor that:
- The specific composition and scope of work performed in accordance with this agreement is indicated in the Order Invoice.
- In case of changes in the design of products relative to the existing one architectural solution buildings, it is necessary to obtain approval from the relevant authorities state power Krasnodar;
- the use of non-opening sashes in window blocks residential premises above the first floor are not allowed, except for doors with dimensions not exceeding 400x800 mm, as well as in products opening onto balconies (loggias) if such structures have devices for ventilation of the premises.

1.5. The Contractor undertakes to install the products at the following address specified by the Customer:

____________________________________________________________________________

2. Obligations of the parties

2.1. The customer undertakes:

2.1.1. Precisely formulate the terms of the order. Carefully read the measurement sheet. If you have questions, clarify them with the measurer and, if necessary, request that appropriate changes be made to the measurement sheet. Check the compliance of the data specified in the measurement sheet with the data in the Order Invoice. Sign the measurement sheet and the Invoice. From the moment the parties sign the above documents, the terms of this agreement on the scope, procedure and conditions of work are considered agreed upon and come into force. The Contractor is not responsible for the correctness and reliability of measurements provided by the Customer independently or performed on the Customer’s instructions by third parties.

2.1.2.Provide to the Contractor the necessary conditions to perform work, including: obtaining all permits and approvals necessary for the installation of products, ensuring access for the Contractor's employees to the installation site of the products specified in clause 1.5 of this agreement at the time agreed upon by the parties; providing lighting for the work site; ensuring the connection of the Contractor's instruments to electrical network(220 V, 50 Hz); freeing the installation site of products from unnecessary items, including: ensuring free access to windows and (or) doorways; covering furniture, floors, walls and other property from construction waste, removing fire hazardous items from the work site.

2.1.3. On the days of delivery and installation, at the time agreed upon by the parties, be at the work site or ensure the presence of your competent representative to carry out actions to accept the results of the work performed.
In the absence of the Customer (his representative) at the work site, the delivery and installation dates of the products are postponed by the Contractor in accordance with his production schedule and re-agreed with the Customer. Repeated delivery of products and departure of the installation team are paid additionally by the Customer.
Downtime of the installation team caused by the Customer’s failure to fulfill the obligations provided for in clause 2.1.2 is paid at the rate of __________ rubles per person/hour.

2.1.4. Ensure the safety of the work acceptance certificate and present it to the installation foreman for execution upon request.

2.1.5.Accept the results of the work performed by the Contractor. If there are any complaints about the quality of the work performed, indicate them in the Work Acceptance Certificate. In case of loss of the work acceptance certificate and (or) refusal to sign it, the work is considered to be actually accepted. Claims regarding defects not specified in the acceptance certificate will not be considered by the Contractor.

2.1.6. Pay for work on time and in full.

2.2. The Contractor undertakes:

2.2.1. Perform the work using your own materials, in the manner and under the conditions specified in the Invoice.

2.2.2. Complete the work within the time period agreed upon by the parties. The deadlines for completing individual stages of work are given on the first page of this agreement.

2.2.3. Issue a Passport for the installed products after the Customer has fulfilled all the terms of this agreement.

2.2.4.Fold construction garbage, remaining after dismantling old products and installing new ones in bags. Removal and disposal of waste remaining after the dismantling of old products and installation of new products is carried out by the Customer.

2.3. The transfer of work results by the Contractor and their acceptance by the Customer is recorded:
- work on the production and delivery of products in the invoice;
- work on installation of products and additions, finishing of slopes in Work Acceptance Certificates.

3. Cost of work and payment procedure.

3.1. The total cost of the work is agreed upon by the parties and is shown in the Invoice. Settlements between the parties are made in Russian rubles.

3.2. The Customer undertakes to pay the total price agreed upon by the parties in the following order: 70% (seventy) percent of the total cost of work is paid by the Customer in cash in cash to the Contractor's cash desk at the time of signing this agreement. The remaining 30% (thirty) percent of the total cost of work is paid by the Customer in cash to the Contractor's cash desk the next day after acceptance of the work performed. Ownership of the products passes to the Customer upon full payment. If the Customer fails to comply with the deadlines for making an advance payment, the deadlines for completing the work under this contract are postponed for the duration of the delay in payment.

4. Acceptance of results of work performed.

4.1. Acceptance of the results of completed work is carried out in stages: acceptance of products, acceptance of the results of installation of products and additions, finishing of slopes.

4.2. The Contractor undertakes to deliver within the time specified in the “Delivery Date” column finished goods to the address specified in clause 1.5 of this agreement and present the products for inspection and quality control to the Customer. The Customer is obliged, with the participation of a representative of the Contractor, to inspect the products, check their quality and compliance of the products with the terms of the Order Invoice. If there are no claims on the part of the Customer regarding the quality and compliance of the products with the terms of the Invoice, the Customer is obliged to sign the invoice. If the Customer has any complaints about the quality and compliance of the products with the terms of the Invoice, appropriate marks are made on the reverse side of the invoice, certified by the signature of the Customer (his representative) and the signature of the Contractor’s representative. Elimination of identified deficiencies is carried out by the Contractor free of charge within a reasonable period of time, not exceeding 10 (ten) working days from the date of signing the invoice. In exceptional cases (lack of necessary materials, components and similar circumstances beyond the control of the Contractor), the period for eliminating deficiencies may be extended, but not more than by 10 (Ten) working days. From the moment the invoice is signed, the product is in the custody of the Customer and the risk of accidental loss or damage to the product passes to the Customer.
In the event of an unreasonable refusal by the Customer to sign the invoice, the product is returned to the Contractor's warehouse and is retained by the Contractor until the dispute is resolved. Repeated delivery of the product is carried out at the expense of the Customer, and installation of the product is carried out after one hundred percent payment of the total cost of work and additional costs incurred by the Contractor as a result of the Customer’s unreasonable refusal to accept the work performed.

4.3. After completing each stage of work (installation of products, installation of additions, finishing of slopes), the Customer is obliged, together with a representative of the Contractor, to inspect and check the quality of the work performed, and if there are no complaints, sign the Acceptance Certificate for the corresponding stage.*
If the Customer has any complaints about the quality of the work, the parties make appropriate notes in the Acceptance Certificates.
Elimination of deficiencies in the work is carried out within the time limits provided for in clause 4.2 of this agreement.

5. Responsibility of the parties

5.1. All disputes and disagreements under this agreement are resolved by the parties through negotiations. If the parties do not reach a common agreement, the dispute is referred to the court in accordance with the legislation of the Russian Federation.

5.2. For failure to fulfill or improper fulfillment of obligations, the parties are liable in accordance with the current legislation of Russia.

5.3. For late or incomplete payment for work performed, the Customer is liable in the form of
a penalty in the amount of 0.1% (zero point one percent) of the amount payable for each day of delay in payment, but not more than the total cost of the work.

5.4. The Contractor is not responsible for non-compliance of the results of the work performed with the requirements specified in clause 1.4 of this agreement, if, despite the warning given, the Customer does not change his requirements before signing the Invoice.

* If the Order Invoice does not provide for the obligation to perform work on sealing slopes, the Contractor does not carry out work on waterproofing and vapor barrier of the assembly joint. In this case, the Customer bears the risk negative consequences from the lack of such isolation.

6. Final provisions

6.1. This agreement comes into force from the moment of signing and is valid until the parties fully fulfill their obligations.

6.2. In all other respects that are not regulated by this agreement, the parties are guided by the current legislation of the Russian Federation.

7. List of documents that are an integral part of this agreement.

7.1.Measurement sheet.
7.2. Invoice order.
7.3.Invoice.
7.4. Acceptance certificates.
7.5. Product passports.
7.6. Warranty card.

The order invoice and two copies of the work acceptance certificate were handed over to the Customer at the time of signing this agreement. One copy of the work acceptance certificate after signing by the parties must be returned to the Contractor. In case of failure to return one copy of the acceptance certificate to the Contractor, the Customer will not be issued passports for the products. In this case, the issuance of passports for products is carried out only after the restoration of the acceptance certificate for the work performed.

8. Details and signatures of the parties.